Catappult logo
Catappult logo
language selectorEn
Catappult logo

Catappult Certified Developer Distribution Agreement


Last updated: May 2024

Catappult is a software developed by Aptoide S.A. (“Aptoide”), a company with ID 509987184 and principal place of business at Rua Soeiro Pereira Gomes, Lote 1, 3D, 1649-031 Lisboa, Portugal which allows the distribution of products in the Aptoide App Store, Aptoide App Store iOS and other Apps distribution channels. Catappult is a product developed and owned by Aptoide.

By uploading or otherwise making available applications or any other materials under this Agreement, you (on behalf of yourself or the business you represent) agree to be bound by the terms of this Agreement. As used in this Agreement, "we" and "us" means Aptoide or any of its affiliates, and “you” and "Certified Developer" means the applicant (if registering as an individual), or the business employing the applicant (if registering as a business). Capitalized terms have the meanings listed in the Definitions below.

Definitions

Apps: Software, content and digital materials developed or distributed by the Certified Developer distributed via Catappult, including the respective metadata and the digital content or digital goods which the Users may purchase within such Apps.

Aptoide App Store: Software developed and provided by Aptoide which can be accessed by Devices and gives access to the Apps, either through Aptoide website or Aptoide App.

Aptoide App Store iOS: The Aptoide App Store developed and provided by Aptoide for iOS. Store.

Aptoide Partner: Any person or company who is registered and approved by Aptoide to have access to Catappult content and distribute Apps in the Partner App Store.

AppCoins Wallet: Aptoide’s own payment system used to process payments from end users in the Aptoide App Store and Partner Stores.

AppCoins Credits: A virtual currency used to make in-app purchases in your Apps.

Catappult: The software developed by Aptoide which allows Certified Developers to distribute and monetise their Apps in the Aptoide App Store and Partner Stores.

Certified Developer: The developer or distributor of Apps which has adhered to the Aptoide Developers Program through which its Apps are certified by Aptoide, having access to advanced tools for the distribution of Apps and in-app billing.

Certified Developer Account: An account issued to Certified Developers that enables the distribution of Apps in Catappult.

Device: Any device that can access the Aptoide App Store, the Aptoide App Store iOS or Partner Stores, as defined herein.

In-App Products: Items and/or services Users can purchase in the Apps.

MoR Territories: The countries listed in Annex I of this Agreement. Aptoide reserves the right to unilaterally add additional countries to Annex I of this Agreement without the need for a formal amendment to this Agreement. The updated list of MoR Territories is made available to Developer at the Certified Developer Account.

Partner Stores: Aptoide Partner App Store for the distribution of Apps.

Services: The services provided by Aptoide in relation to the distribution of Apps via Catappult.

Transaction Taxes Territories: The countries listed in Annex II of this Agreement. Aptoide reserves the right to unilaterally add additional countries to Annex II of this Agreement without the need for a formal amendment to this Agreement. The updated list of Transaction Taxes Territories is made available to Developer at the Certified Developer Account.

Transaction Taxes: Taxes that are imposed on the purchase price of goods, such as value-added taxes (VAT) and withholding taxes.

Users: The device owners who access the Aptoide App Store or the Aptoide Partner Stores in their devices, which download and use the Apps.

Wallet Account: A digital wallet which supports the Certified Developer’s balance. Certified Developers must maintain their Wallet Account operational.

1. Introduction

1. Aptoide has developed the Certified Developers Program which consists of the certification of Developer’s Apps. Only certified Apps may be distributed via Catappult.

2. Access to Catappult is limited to professional users who intend to make their Apps available not only in the Aptoide App Store, but also in the Aptoide Partner Stores.

3. Catappult is a SaaS (Software as a Service) developed for professionals which allows the distribution of Apps. By registering in Catappult, or when you log-in for the first time in Catappult with your credentials, a Wallet Account will be associated to your Certified Developers Account. All your transactions made through Catappult will be managed by such Wallet Account.

4. If your Apps are paid or include paid In-App Products you must integrate Catappult’s billing into your Apps. For that effect, you will have to provide to Aptoide specific data about your Apps via the Catappult Console (such as, but not limited to, Apps package name provided to Google Play, the pricing of the Apps or in-app purchases). You undertake to make available to Aptoide, or to provide Aptoide with the necessary authorizations to obtain, all information necessary for that effect and acknowledge that Aptoide cannot be held liable for any delays, damages or losses related with the lack of availability of such information.

2. Accepting this Agreement

1. This agreement ("Agreement") forms a legally binding contract between you and Aptoide in relation to distribution of Apps via Catappult. In order to distribute Apps via Catappult, you must first agree to this Agreement by accepting it online (through the button “I accept”). You may not distribute Apps on Catappult if you do not accept this Agreement.

2. Use of Catappult and Services is limited to parties that lawfully can enter into and form contracts under applicable law.

3. You represent and warrant that: (a) if you are a business, you are duly organized, validly existing and in good standing under the laws of the country in which your business is registered; and (b) you have all requisite right, power and authority to enter into this Agreement and perform your obligations hereunder.

3. Distribution of Apps

1. You can distribute Apps through Catappult, by uploading them to your Certified Developer Account.

2. By entering into this Agreement, you agree that by uploading Apps to Catappult they will be automatically available in Aptoide App Store and, if you choose so, in Aptoide App Store iOS and all Aptoide Partner Stores which have access to Catappult. You can choose in which specific Aptoide Partner Stores your Apps will be distributed by changing the distribution settings on your Certified Developer Account.

3. Certified Developer understands and agrees that Aptoide Partner Stores may decide to stop distributing the Apps in their App Stores at any moment, upon their sole discretion. The suspension or termination of distribution of the Apps by a certain Aptoide Partner Store will not affect the validity and effectiveness of this Agreement, under which Certified Developer may continue to distribute its Apps in other App Stores.

4. Through your Certified Developer Account, you can distribute Apps owned by you and/or Apps in relation to which you were granted with a distribution licence by the respective owner. You represent and warrant that you have all intellectual property rights, including all necessary patent, trademark, trade secret, copyright or other proprietary rights, in and to the Apps. If you use third-party materials, you represent and warrant that you have the right to distribute the third-party material in the App. You agree that you will not submit material to Catappult that is copyrighted, protected by trade secret or otherwise subject to third party proprietary rights, including patent, privacy and publicity rights, unless you are the owner of such rights or have permission from their rightful owner to submit the material.

5. You agree to use Catappult for distribution of Apps only for purposes that are permitted by: (a) this Agreement, and (b) any applicable law, regulation or generally accepted practices or guidelines in the relevant jurisdictions.

6. It is your sole responsibility to provide Apps that do not violate any copyright, trademark, trade secret, trade dress, patent or other intellectual property right of any person or defames any person or violates their rights of publicity or privacy. As referred to below, Aptoide will not be liable for any infringement in such respect.

7. The distribution of Apps through Aptoide Partner Stores may be subject to the terms and conditions set out by such Partner Stores, to which you will have to adhere, as may be requested by Aptoide Partner Stores from time to time.

8. Updating Apps. You are solely responsible for your Apps updates whenever there is an update that needs to be submitted to Catappult. If an App update is not intended to go live on Aptoide App Store or Aptoide’s Partner Stores, you must inform Aptoide accordingly. You acknowledge that Aptoide cannot be held liable for any delays, damages or losses related with the submission of your Apps updates. In case you distribute paid Apps and In-App Products, you understand and agree that maintaining the Catappult billing integration in your Apps is of essence and you undertake, during the term of the agreement and for a reasonable period thereafter, not to distribute updated Apps or perform any other actions that will cause removal, blocking or otherwise prevent the integration of Catappult billing system and the distribution of the Apps as provided for in this agreement.

9. Privacy of Device Users. You agree that by distributing Apps you will protect the privacy and legal rights of Users. If Users provide you with, or the App accesses or uses, user names, passwords, or other login information or personal information, you must inform Users that the information will be available to your Apps, and you must provide legally adequate privacy notice and protection to Users. Further, the Apps may only use that information for the limited purposes for which the User has given you permission to do so. If the Apps store personal or sensitive information provided by Users, it must do so securely and only for as long as it is needed. If the User has opted into a separate agreement with you that allows you or the Apps to store or use personal or sensitive information directly related to the Apps (not including other products or applications) then the terms of that separate agreement will govern your use of such information. If the User provides the Apps with their Aptoide account information, the Apps may only use that information to access the User's Aptoide account when, and for the limited purposes for which, the User has given you permission to do so. Aptoide owns all information related to Aptoide App Store Users and to the transactions entered with such Users; Aptoide may share this information with you, following the execution of a specific agreement, if that is allowed by the applicable laws.

10. Prohibited Actions. You agree that while using Catappult you will not engage in any activity, including the publishing or distribution of Apps, that interferes with, disrupts, damages, or accesses in an unauthorized manner the devices, servers, networks, or other properties or services of any third party including, but not limited to, Device users and Aptoide. You may not use information obtained from the Aptoide’s Users accounts to sell or distribute Apps outside Catappult.

11. Non-Compete. You may not use Catappult to distribute or make available any Product which primary purpose is to facilitate the distribution of software applications and games for use on Android Devices outside of Catappult.

12. You agree that you are solely responsible for (and that Aptoide has no responsibility to you or to any third party for) any breach of your obligations under this Agreement, any applicable third-party contract or terms of service, or any applicable law or regulation, and for the consequences (including any loss or damage which Aptoide or any third party may suffer) of any such breach.

13. Product Ratings. Aptoide App Store allows Users to rate Apps. Aptoide App Store is designed to rank first the Apps with higher rating; this means that the Apps with the highest ranking given by Users will be presented in a more prominent way to Users of the Aptoide App Store. Your Apps may be subject to User ratings to which you may not agree. You may contact Aptoide if you have any questions or concerns regarding such ratings in the Aptoide App Store. The ranking of the Apps in Partners Store and Aptoide Partner Stores is subject to the terms and conditions of such App Stores and Aptoide not does not have any intervention on the determination of the parameters and criteria used to rank Apps in those App Stores. Certified Developer shall consult Aptoide Partner Stores terms and conditions in order to be informed about the Apps ranking criteria applied on those App Stores.

14. Marketing Your Apps. You will be responsible for uploading your Apps to your Certified Developer Account, providing required Product information, and accurately disclosing the security permissions necessary for the App to function on Devices.

15. Restricted Content. Apps and other materials made available while using the Services (“Content”) must comply with the following:

  1. Sexual Content: Content cannot contain or promote sexual content or profanity, including pornography, or any content or services intended to be sexually gratifying. Content that contains nudity may be allowed if the primary purpose is educational, documentary, scientific or artistic, and is not gratuitous.
  2. Child Endangerment: Content that sexualizes minors, including but not limited to, Content that promotes pedophilia or inappropriate interaction targeted at a minor (e.g. groping or caressing) is not allowed.
  3. Hate Speech: Content cannot promote violence or incite hatred against individuals or groups based on race or ethnic origin, religion, disability, age, nationality, veteran status, sexual orientation, gender, gender identity, or any other characteristic that is associated with systemic discrimination or marginalization.
  4. Violence: Content cannot depict or facilitate gratuitous violence or other dangerous activities nor be related to terrorism, such as content that promotes terrorist acts, incites violence, or celebrates terrorist attacks. Content that depict fictional violence in the context of a game, such as cartoons, hunting or fishing, are generally allowed.
  5. Dangerous Products: Content cannot facilitate the sale of explosives, firearms, ammunition, or certain firearms accessories or instructions for the manufacture of explosives, firearms, ammunition, restricted firearm accessories, or other weapons.
  6. Alcohol, tobacco and drugs: Content cannot facilitate the sale alcohol, tobacco or drugs or encourage the illegal or inappropriate use of alcohol or tobacco.
  7. Financial Services: Content cannot expose users to deceptive or harmful financial products and services.
  8. Gambling: Content and services that facilitate online gambling may be allowed to be distributed in certain locations and if it meets certain requirements which are analysed on a case-by-case basis and subject to applicable laws and other criteria.
  9. Illegal activities: Content cannot promote or facilitate illegal activities.
  10. Intellectual Property: Content cannot violate intellectual property rights, including patent, copyright, trademark, trade secret, or other proprietary right of any party or encourage or induce infringement of intellectual property rights.
  11. Privacy: Content must comply with all applicable local laws, the European Union’s General Data Protection Regulation (GDPR).

You also undertake not to upload or otherwise make available Apps or any other materials that:

  1. contain viruses, trojans, spyware, adware, ransomware, rootkits, back doors, worms and any other malware or any similar mechanism or device, or any other code designed or intended to have, or intended to be capable of performing, any of the following functions: (a) disrupting, disabling, harming, or otherwise impeding in any manner the access to or the operation of, or providing unauthorized access to, a computer system or network or other device on which such code is stored or installed; or (b) accessing, copying, blocking, encrypting, damaging or destroying any data or file, in each case, without the user’s consent.
  2. harm user devices or personal data.
  3. create unpredictable network usage that has an adverse impact on a user's service charges or a telecommunications network.
  4. knowingly violate telecommunications carrier's terms of service for allowed usage.
  5. create a spammy user experience, whether by posting repetitive content or misleading information about an App's purpose.

In case Aptoide detects Content that does not comply with these Terms, Aptoide may, without prejudice of Aptoide’s rights to terminate any agreement with you, remove or disable access to such Content.

We may report any activity that we suspect violates any law or regulation to appropriate law enforcement officials, regulators, or other appropriate third parties. Our reporting may include disclosing appropriate user information. We also may cooperate with appropriate law enforcement agencies, regulators, or other appropriate third parties to help with the investigation and prosecution of illegal conduct related to alleged violations of these Terms.

16. Support. You will be solely responsible to provide Users with support and maintenance of your Apps and to handle any complaints about your Apps. Your contact information will be displayed on each App detail page and will be made available to Users for customer support purposes. You undertake to provide and maintain valid and accurate contact information to be made available to Users.

17. Reinstalls. Users are allowed unlimited reinstalls of each App distributed through Catappult, provided however that if you remove Apps from the Catappult, such Apps shall be removed from all portions of the Catappult and Users shall no longer have a right or ability to reinstall the affected Apps.

4. Additional Terms for Distribution in Aptoide App Store iOS

1. This section is solely applicable to Certified Developers who decide to distribute Apps through Aptoide App Store iOS.

2. If you choose to distribute Apps through Aptoide App Store iOS you acknowledge and agree that prior to making your Apps available in Aptoide App Store iOS for distribution to End Users, your Apps will have to be previously approved by Apple in accordance with Apple’s procedures and requirements.

3. You undertake to make available to Aptoide, or to provide Aptoide with Apps that are compliant with Apple’s terms and conditions, namely, but not limited to, the Apple Developer Program License Agreement (available here: https://developer.apple.com/support/terms/apple-developer-program-license-agreement/#S2 ), as applicable, and to provide Aptoide with the necessary information, authorizations and support to obtain approval of your Apps for distribution in Aptoide App Store iOS. You acknowledge that Aptoide cannot be held liable for any delays, damages or losses related with the Apps approval process by Apple and/or the lack of approval of your Apps by Apple.

4. You further acknowledge and agree that:

  1. The distribution of your Apps through the Aptoide App Store iOS will be limited to the territory of the European Union.
  2. For the purposes of Clause 5.1. and 5.3. of this Agreement, Aptoide will, acting as your agent and with you acting as Principal, act as the merchant of record for the Apps and In-App Products sold to End Users through the Aptoide App Store iOS, being applicable the corresponding terms and conditions provided for in Clause 5 of this Agreement.
  3. In addition to the terms and conditions provided for Clause 9 of Agreement (“Product Takedowns”) Apple’s terms and conditions are applicable to your Apps and Aptoide will be entitled to remove your Apps from future distribution through the Aptoide App Store iOS in case Apple, in its sole discretion, determines that your Apps are not compliant with Apple’s terms and conditions. You acknowledge that Aptoide cannot be held liable for any damages or losses related with the removal of Apps from the Aptoide App Store iOS when determined by Apple.

5. You certify that each of the Apps You deliver to Aptoide for distribution in the Aptoide App Store iOS is authorized for export from the United States to anywhere in the European Union where You distribute, in accordance with the requirements of all applicable laws, including but not limited to the United States Export Administration Regulations, 15 C.F.R. Parts 730-774 and the Applicable European Laws. You further represent and warrant that all versions of the Apps are not subject to the International Traffic in Arms Regulations 22 C.F.R. Parts 120-130 and are not designed, made, modified or configured for any military end users or end uses as defined and scoped in 15 C.F.R § 744. Without limiting the generality of this Clause, You certify that: (i) none of the Apps contains, uses or supports any data encryption or cryptographic functions; or (ii) in the event that any Apps contains, uses or supports any such data encryption or cryptographic functionality, You certify that You have complied with the United States Export Administration Regulations as well as the applicable European laws, and are in possession of, and will, upon request, provide Aptoide with PDF copies of export classification rulings (“CCATS”) issued by the United States Commerce Department, Bureau of Industry and Security (“BIS”) or any self-classification reports submitted to the BIS, and appropriate authorizations from other regions that mandate import authorizations for those Appls, as required.

6. You further represent and warrant that the Apps do not infringe Apple’s intellectual property or appear confusingly similar to the Apple App Store or an Apple product, service, interface, computer software application, or advertising theme. You shall not apply for or register a trademark, service mark, or copyright for or incorporating an Apple trademark, service mark, graphic symbol, logo, icon, trade dress, slogan, or similar variation as a company, product, or service name. You shall not, indirectly or directly, suggest or imply that Apple recommends, endorses, or sponsors You or your Apps. Absent an express written license, use of an Apple trademark, service mark, trade dress, slogan, graphic symbol, logo, icon, or similar variation in a manner suggesting or implying affiliation, endorsement, or sponsorship by Apple violates the terms of this Clause.

5. Commercial relationship, Sale of Apps and In-App Products

1. Under this Agreement You appoint Aptoide to act as your commercial agent to make your Apps, including In-App Products, available in the Aptoide App Store, Aptoide App Store iOS and in Partner Stores.

2. This Agreement applies to free and paid Apps and In-App Products made available to Users. In case you distribute paid Apps and paid In-App Products, you will have to integrate Catappult billing solution into your Apps and you undertake to keep such integration as provided for in this Agreement.

3. If you choose to do so in your Certified Developer Account, Aptoide, acting as your agent and with you acting as Principal, is the merchant of record for the Apps and In-App Products sold to Users located in MoR Territories through the Aptoide App Store, Aptoide App Store iOS and Partner Stores. In case you make available Apps and In-App Products to Users located in all other territories and/or in Partner Stores which have not integrated Catappult’s billing system, you are the merchant of record for the Apps and In-App Products sold to Users.

4. In cases where Aptoide acts as merchant of record, Aptoide will determine if the Apps and In-App Products are subject to Transaction Taxes and, if so, the applicable tax rate will be collected by Aptoide and remitted to the appropriate tax authorities. Aptoide will issue invoices for the individual transactions entered into with the Users.

5. In addition to the above, and solely in relation to the sale of Apps and In-App Products to Users located in the Transaction Taxes Territories through the Aptoide App Store and certain Partner Stores, Aptoide may, if you choose so in your Certified Developer Account, determine if the Apps and In-App Products are subject to Transaction Taxes and, if so, the applicable tax rate will be collected by Aptoide and remitted to the appropriate tax authorities. In case you make available Apps and In-App Products to Users located in all other territories and/or in Partner Stores which have not integrated Catappult’s billing system, you are solely responsible to determine, collect and remit to the applicable authorities all Transaction Taxes.

6. In cases where you act as merchant of record, Aptoide acting as your commercial agent and You acting as principal, You acknowledge that:

  1. The prices set by You shall be inclusive of all taxes.
  2. Any contract to sell Apps and In-App Products is made only between You and the User concerned and Aptoide is not a party to any such contract.
  3. Apps or In-App Products offered for sale through Catappult are neither owned nor come into the possession of Aptoide at any time.
  4. You are solely liable to determine, collect and remit to the applicable governmental tax authorities all Transaction Taxes or charges imposed by any government entity in connection with the sale of In-App Products and to comply with any other tax obligations related with such sale. Notwithstanding, where there is a legal obligation to do so, Aptoide will withhold the applicable Transaction Taxes from the In-App Products price and remit such Transaction Taxes to the competent authorities in such country/territories. In such cases, Developer will be informed about the applicable Transaction Taxes rates. Developer will still be responsible for complying with any other tax obligations applicable in such countries/territories

7. The price of the Apps and In-App Products is determined by You, at your sole discretion, and may be set in US Dollars (USD) or other local currencies. Aptoide may display to Users the price of Apps and In-App Products in their native currency. In these cases, the currency and conversion rates will be the ones available at https://exchangeratesapi.io/ and are automatically updated daily. Because the currency and conversion rates are provided by an external third party, Aptoide is not responsible for the accuracy of currency rates or conversion.

8. You will be responsible to declare, withhold and pay to the appropriate tax authorities any income taxes due by You as a result of this Agreement.

9. Self-Invoicing. Where Clauses 4.3., 4.4. and 4.5. of this Agreement are applicable to you, you agree that Aptoide will have in place a self-invoicing system during the term of the Agreement or as long as Aptoide Clauses 4.3., 4.4. and 4.5. are applicable. You expressly authorize Aptoide to issue on your name and on your behalf all invoices relating to the acquisition of the Apps and In-App Products by Aptoide which are sold to Users in accordance with the requirements of the applicable legislation. You undertake to provide Aptoide with updated and accurate invoicing details and to inform Aptoide, within 3 (three) business days of any amendments to such details.

10. Special Refund Requirements. ou authorize Aptoide to give Users a full refund of the App price if the User requests the refund within 2 (two) hours after purchase.

11. Chargebacks. A chargeback is a process that may lead to the return of funds to a User. This process is initiated by the User, asking the issuing bank the refund. Issuing bank will then contact the payment processor which will then notify Aptoide. Whenever Aptoide receives a chargeback notification related with a sale of an App, Aptoide will inform you accordingly and you undertake to provide to Aptoide, within the term determined by the payment processor, with the necessary documents to dispute the chargeback. Aptoide will submit the documents provided to the payment processor, which will decide if it is possible to reverse the chargeback. If it is resolved that the chargeback is not reversible, the refund (correspondent to the revenue share you would receive for the disputed transaction) will be deducted to the revenue share due to you. Information about the refund in case of a chargeback will be marked in your Certified Developer Account as “chargeback”. Please note that the chargeback process is managed and resolved by the payment processor and the issuing bank and that Aptoide does not have any power to dispute the decisions taken.

6. Apps Revenue Share

1. This Agreement covers the share of the revenue generated by the sale of Apps and In-App Products. In case you choose to distribute free Apps and/or In-App Products, this clause will not be applicable.

2. The price you set for Apps and In-App Products will determine the amount of payment you will receive. The amount to be paid to you for the sales made through Catappult is equal to the gross sales price less the share due to Aptoide and the refunds and chargebacks requested by Users. The information about the In-App Products sales, respective revenue share due to You, refunds and chargebacks will be available at your Certified Developer Account.

3. Applicable revenue shares. The revenue share applicable to the distribution of Apps in Aptoide App Store and Partner Stores is defined in Annex III of this Agreement. The revenue share applicable to the distribution of Apps in Aptoide App Store iOS is defined in Annex IV of this Agreement.

4. Payment of revenue share. Your Wallet Account will be credited in US Dollars at the moment of each transaction with the amount corresponding to your revenue share. Aptoide will provide you, within 10 business days as from the end of each calendar month with a report (available in your Certified Developer Account, or sent by e-mail) detailing the volume of In-App Product sales, refunds, chargebacks and the total amount of revenue share due to You referring to the previous calendar month.

In case there is a dispute in relation to the amount of revenue share due to You, you must notify Aptoide within 5 days after the date of delivery of the monthly report. The dispute notification shall contain all the details regarding the dispute and the reasons thereof and the relevant proof in support of its dispute. The Parties shall collaborate in good faith in order to resolve the dispute within a reasonable term. In case of a dispute related to the revenue share due to You, Aptoide reserves the right to withhold payments until such dispute is resolved. If you fail to notify Aptoide within said term, it is deemed that You have accepted the amount of revenue share provided for in the monthly report. Aptoide will process the payment of the revenue share within 30 days as from the date of acceptance of the monthly report.

5. In the event the Agreement is terminated, you may request the withdraw of the existing balance from your Wallet Account up to (30) days after the end of the calendar month in which the Agreement is terminated

6. If you are past due on any payment to Aptoide, Aptoide reserves the right to withhold payments until all outstanding payments have been made or to offset amounts owed to you in connection with the Program by amounts owed by you to Aptoide.

7. You will bear the bank fees, costs or taxes charged to Aptoide relating to payments made to you. Aptoide will be entitled to deduct such fees from payments due to you or to charge such fees separately.

8. As a security measure, we may, impose transaction limits relating to the value of any transaction or withdrawal, the cumulative value of all transactions or withdrawals during a period of time, the number of transactions or withdrawals per day or other period of time, or we may request additional documentation from you in order to complete the transactions or withdrawals. We will not be liable to you: (i) if we do not proceed with a transaction or withdrawal that would exceed any limit established by us for a security reason, or (ii) if we allow a User to withdraw from a transaction or to be refunded from a transaction due to an error of processing occurred in the Apps, Catappult, Aptoide App Store or in the Partners Store.

9. By entering into this Agreement, you agree that the revenue share set out in clause 6 is only applicable to the sale of Apps made through Catappult.

7. Catappult Fee

1. You undertake and agree to pay an annual fee to Aptoide as a consideration for the distribution of your Apps through Catappult. Catappult fee is refundable in the first 30 days and before any of your Apps starts to be distributed in Catappult.

2.The amount of the fee to be paid to Aptoide is determined at https://docs.catappult.io/docs/subscription and is also available at your Certified Developer Account.

3. Payment of the annual fee is due when you first subscribe to Catappult services and will be due every subsequent year on the same date.

4. You must provide all the necessary information for Aptoide to be able to issue an invoice with the corresponding amount of your annual fee, namely:

  1. Company registered name;
  2. Company Tax Identification Number (TIN);
  3. Company Address, including zip code and country of incorporation.

5. The payment of the annual fee due to Aptoide may be performed through your Certified Developer Account by using your credit card, Paypal account or other payment methods accepted by Aptoide’s payment processing providers.

6. Aptoide may provide you other services related with Catappult platform. The specific terms and conditions applicable to such services will be communicated to you by Aptoide. Aptoide will not provide you with additional services unless you have specifically asked for the provision of such services and agreed to the respective terms and conditions.

7. Failure to pay Catappult fee prevents the submission and release of new Apps in your Certified Developer Account.

8. License Grants

1. Certified Developer Licenses. Certified Developer grants to Aptoide a non-exclusive, worldwide and royalty-free license to: (i) distribute the Apps via Catappult; (ii) make the Apps available for download by Users; and (iii) copy, perform, display, and use the Apps for administrative and demonstration purposes; (iv) use the Certified Developer trademarks, logos and commercial names in presentations, marketing materials, customers’ lists and Web site listings of customers and Referral Pages; (v) use Certifies Developer trademarks, logos and commercial names to announce the launch and distribution of the Apps in press releases and on Aptoide’s social media channels. Aptoide undertakes to use Certified Developer trademarks solely in the manner in which they were provided to Aptoide, meaning that Aptoide may not change, alter, amend, vary, or modify the trademarks in any way, at any time

2. Aptoide Licenses. Aptoide grants to Certified Developer a limited, revocable, non-sublicensable, non-assignable, non-exclusive and royalty-free license to: (i) access and use Catappult in the manner permitted by this Agreement; (ii) install, copy, and use any Aptoide materials we may provide, solely in conjunction with your access to and use and operation of your Certified Developer Account; (iii) enable the access to and use of your Apps by Users; and (iv) use the Aptoide trademarks solely in connection with your use of the Services for which the Aptoide trademarks were provided to you. You must use the Aptoide trademarks solely in the manner in which they were provided to you.

3. Aptoide reserves the right to determine and control all aspects (including all functionality) of Catappult and of the Aptoide App Store as well as the right to re-design, modify and remove any or all aspects of them.

4. You may not and may not authorize any other party to do the following to or with Catappult, the Aptoide App Store or other materials provided by Aptoide: (a) reverse engineer, decompile, or disassemble them; (b) modify or create derivative works based upon them in whole or in part; (c) distribute copies of them; (d) remove any proprietary notices or labels on them; or (e) resell, lease, rent, transfer, sublicense, or otherwise transfer rights to them. In addition to any other rights or remedies that we may have, any use in violation of this section will immediately terminate your right to use Catappult.
All licenses not expressly granted in this Agreement are reserved and no other licenses, immunity or rights, express or implied are granted by us, by implication, estoppels or otherwise.

5. EULA. Certified Developer shall license to Users the right to use the Apps. Certified Developer shall implement such license in its Apps (“Developer’s EULA”). In case Certified Developer has not implemented a Developer’s EULA in its Apps, then the Standard EULA Terms, which specify, among other things, that you are the licensor of the Apps and that we are not parties to your EULA, will constitute the entire EULA for the purposes of distributing Apps in the Aptoide App Store, will apply. The Standard EULA Terms include the following end user license terms:

  1. The Developer is the licensor of the App.
  2. If the App does not include a Developer EULA that specifies license rights, Developer grants to user a limited, non-transferable license to download and use the App only for personal and non-commercial purposes.
  3. You may not modify, reverse engineer, decompile or disassemble the App in whole or in part, or create any derivative works or sublicence any rights in the App, unless otherwise expressly authorised by the Developer.
  4. The App is protected by copyright and other intellectual property laws and treaties. Unless otherwise expressly stated in the Developer’s EULA, Developer or its licensors own all title, copyright, and other intellectual property rights in the App, and the App is licensed, not sold.
  5. The end user acknowledges and agrees that Aptoide has no responsibility or liability with respect to your use of the App or any content or functionality in the App.

You agree that the distribution of Apps through Partners Stores may be subject to other end user license terms, as may be determined by such third parties. The Standard EULA Terms will specify, among other things, that you are the licensor of the Apps and that we are not parties to your EULA. If there are any conflicts between the Standard EULA Terms and the Developer’s EULA, then to the extent of such conflict the Standard EULA Terms will control for the purposes of distributing Apps in the Aptoide App Store. We do not have any responsibility or liability related to compliance or non-compliance by you or any user under a Developer’s EULA or the Standard EULA Terms.

6. All licenses not expressly granted in this Agreement are reserved and no other licenses, immunity or rights, express or implied are granted by the parties, by implication, estoppels or otherwise.

9. Product Takedowns

1. Your Takedowns. You may remove your Apps from future distribution through Catappult at any time, but you must comply with this Agreement. Removing your Apps from future distribution through Catappult does not: (a) affect the rights licensed to Users who have previously purchased or downloaded your Apps; (b) remove your Apps from Devices or from any part of the Catappult where previously purchased or downloaded applications are stored on behalf of Users; or (c) change your obligation to provide Apps support or services that have been previously purchased or downloaded by Users. Notwithstanding the foregoing, in no event will Aptoide maintain on any portion of the Catappult (including, without limitation, the part of the Catappult where previously purchased or downloaded applications are stored on behalf of Users) any paid Product that you have removed from Catappult and provided written notice to Aptoide that such removal was due to: (i) an allegation of infringement, or actual infringement, of any copyright, trademark, trade secret, trade dress, patent or other intellectual property right of any person; (ii) an allegation of defamation or actual defamation; (iii) an allegation of violation, or actual violation, of any third party's right of publicity or privacy; or (iv) an allegation or determination that such App does not comply with applicable law.

2. Aptoide Takedowns. If Aptoide is notified by you or otherwise becomes aware that an App or any portion thereof: (a) violates the intellectual property rights or any other rights of any third party; (b) violates any applicable law or is subject to an injunction; (c) violates Aptoide's policies or other terms of service as may be updated by Aptoide from time to time in its sole discretion; (d) is being distributed by you improperly; (e) may create liability for Aptoide; (f) is deemed by Aptoide to have a virus or is deemed to be malware, spyware or have an adverse impact on Aptoide's infrastructure; (g) violates the terms of this Agreement or the terms of the Partners Program; or (h) the display of the App is impacting the integrity of Aptoide servers (i.e., users are unable to access such content or otherwise experience difficulty), Aptoide may remove the App from the Catappult and the Aptoide App Store and will notify you accordingly. Such notification will establish one or more of the foregoing grounds to takedown and will include the rationale underneath the decision.

3. If you believe that the App was removed as a result of a mistake or misidentification, you will be entitled to request the re-integration of the App removed by submitting a request by e-mail to support@catappult.io, which shall be accompanied by sufficient evidence showing that the grounds to takedown are not verified.

4. In the event that your App is involuntarily removed because it is defective, malicious, infringes intellectual property rights of another person, defames, violates a third party's right of publicity or privacy, or does not comply with applicable law, and a User purchased such App within a year before the date of takedown: (i) you must refund Aptoide, all amounts received, plus any associated fees (i.e. chargebacks and payment transaction fees), and (ii) Aptoide may, at its sole discretion, withhold from your future sales the amount in subsection (i) above.

5. Aptoide Partner Stores Takedowns. Your Apps distributed in Aptoide Partner Stores may be subject to takedowns as provided in the Aptoide Partner Stores terms and conditions. You shall contact the providers of such App Stores in case you understand that the takedown of your Apps should not have occurred.

6. Repeat Infringers Policy. If Aptoide verifies or is warned of repeat infringement by a Developer of: (a) the intellectual property rights or any other rights of any third party; (b) any applicable law or this Agreement; (c) Aptoide's policies or other terms of service as may be updated by Aptoide from time to time in its sole discretion; (d) repeat upload of Apps containing virus, malware, spyware or which have an adverse impact on Aptoide's infrastructure or are impacting the integrity of Aptoide servers (i.e., Users are unable to access such content or otherwise experience difficulty), Aptoide will terminate the Certified Developer Account and will remove all of such Developer’s Apps from Catappult.

10. Your Credentials

You agree that you are responsible for maintaining the confidentiality of any credentials that may be issued to you by Aptoide or which you may choose yourself and that you will be solely responsible for all applications that are published under your credentials.

11. Privacy and Information

1. Any data collected or processed under this Agreement by Aptoide is made in accordance with Catappult Privacy Policy. Data collected or processed by Aptoide in relation to Aptoide App Store Users is made in accordance with Aptoide App Store Privacy Policy.

2. In case Certified Developer chooses to make available to Users In-App Products through Catappult billing system, Aptoide will have access to certain Users personal data in relation to which the Parties will act as independent data controllers. In such circumstances, the Parties undertake to enter into the data sharing agreement attached as Annex IV.

3. Under this Agreement, Certified Developer may have access, through the Developer Account, to limited aggregate data generated through the use of Catappult which is not personal data.

12. Terminating this Agreement

1. Either you or Aptoide may terminate this Agreement at any time upon delivery of a prior notice with at least ninety (90) days of advance in relation to the date in which termination becomes effective.

2. In case of termination of the Agreement as provided for in the previous paragraph, the Parties agree that during the prior notice period of 90 (ninety) days the Parties will prepare for the termination of the Agreement (the “Transition Period”). The Parties undertake to comply with the obligations provided for in this Agreement during the Transition Period and in particular to:

  1. Certified Developer undertakes: (i) to maintain the Apps available for distribution in Catappult in the same terms as they were being distributed until the termination notice (e.g. in the same Partner Stores, for the same territories, etc.); and (ii) not to make any changes or amendments to the billing of the Apps distributed in Catappult (namely by removing Catappult’s billing from the Apps).
  2. Aptoide undertakes to: (i) ensure that Certified Developer continues to have access to the Certified Developer Account in the same terms as it was provided until the termination notice; (ii) maintain and ensure proper functioning of Catappult billing in the same terms as it was provided until the termination notice.

3. Upon termination of the Transition Period, termination of the agreement will produce its effects. Upon termination of the Agreement: (i) Certified Developer must cease any use of any relevant credentials; and (ii) the Parties will settle accounts.

4. The Parties explicitly declare and acknowledge that compliance with the obligations outlined in paragraphs 2 and 3 of this clause is essential. In the event of a breach of these obligations, the breaching party shall, without being subject to any type of limitation, indemnify and hold harmless the non-breaching party from any and all liabilities, claims, expenses, losses, and damages suffered or incurred by the non-breaching party.

5. Without prejudice of paragraph 1 of this clause, Aptoide may, at any time and with immediate effects, terminate this Agreement with you if:

  1. Aptoide is subject to a legal or regulatory obligation to terminate the provision of its services; or
  2. You have repeatedly infringed the terms and conditions of this Agreement.

6. Termination of the Agreement will not affect the existing rights already accrued to either Party in accordance with provisions concerning the responsibilities and obligations in this Agreement. Based on its own nature, such rights shall survive the expiry or early termination of this Agreement, including but not limited to those in relation to, disclaimer of warranties, limitation of liability as well as indemnification.

13. DISCLAIMER OF WARRANTIES

1. TO THE MAXIMUM EXTENT PERMITTED BY LAW, YOU EXPRESSLY UNDERSTAND AND AGREE THAT THE DISTRIBUTION OF APPS AND THE USE OF CATAPPULT ARE AT YOUR SOLE RISK AND THAT CATAPPULT AND THE APTOIDE APP STORE ARE PROVIDED "AS IS" AND "AS AVAILABLE" WITHOUT WARRANTY OF ANY KIND.

2. YOUR USE OF CATAPPULT IS AT YOUR OWN DISCRETION AND RISK AND YOU ARE SOLELY RESPONSIBLE FOR ANY DAMAGE TO ANY COMPUTER SYSTEM OR OTHER DEVICE OR LOSS OF DATA THAT RESULTS FROM SUCH USE.

3. APTOIDE FURTHER EXPRESSLY DISCLAIMS ALL WARRANTIES AND CONDITIONS OF ANY KIND, WHETHER EXPRESS OR IMPLIED, INCLUDING, BUT NOT LIMITED TO THE IMPLIED WARRANTIES AND CONDITIONS OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE AND NON-INFRINGEMENT.

4. IN TRANSACTIONS WHERE CERTIFIED DEVELOPER ACTS AS MERCHANT OF RECORD, IF A DISPUTE ARISES BETWEEN CERTIFIED DEVELOPER AND THE USERS, YOU RELEASE APTOIDE (AND ITS AGENTS AND EMPLOYEES) FROM CLAIMS, DEMANDS, AND DAMAGES (ACTUAL AND CONSEQUENTIAL) OF EVERY KIND AND NATURE, KNOWN AND UNKNOWN, SUSPECTED AND UNSUSPECTED, DISCLOSED AND UNDISCLOSED, ARISING OUT OF OR IN ANY WAY CONNECTED WITH SUCH DISPUTES.

14. LIMITATION OF LIABILITY

TO THE MAXIMUM EXTENT PERMITTED BY LAW, AND UNLESS OTHERWISE PROVIDED FOR IN THIS AGREEMENT, YOU EXPRESSLY UNDERSTAND AND AGREE THAT APTOIDE, ITS SUBSIDIARIES AND AFFILIATES, AND ITS LICENSORS SHALL NOT BE LIABLE TO YOU UNDER ANY THEORY OF LIABILITY FOR ANY INDIRECT, INCIDENTAL, SPECIAL CONSEQUENTIAL OR EXEMPLARY DAMAGES THAT MAY BE INCURRED BY YOU, INCLUDING ANY LOSS OF DATA, WHETHER OR NOT APTOIDE OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF OR SHOULD HAVE BEEN AWARE OF THE POSSIBILITY OF ANY SUCH LOSSES ARISING. FURTHER, OUR AGGREGATE LIABILITY ARISING OUT OR IN CONNECTION WITH THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREIN WILL NOT EXCEED AT ANY TIME THE TOTAL AMOUNTS PAID BY APTOIDE TO YOU DURING THE PRIOR SIX-MONTHS IN RELATION TO THE PARTICULAR SERVICE GIVING RISE TO THE CLAIM.

15. Indemnification

To the maximum extent permitted by law, you agree to defend, indemnify and hold harmless Aptoide, its affiliates and their respective directors, officers, employees and agents from and against any and all third party claims, actions, suits or proceedings, as well as any and all losses, liabilities, damages, costs and expenses (including reasonable attorney fees) arising out of or accruing from: (a) your use of Catappult in violation of this Agreement; (b) your Apps that infringe any copyright, trademark, trade secret, trade dress, patent or other intellectual property right of any person or defames any person or violates their rights of publicity or privacy; and (c) any and all taxes due by you as a result of this Agreement, which are not the Transaction Taxes where Aptoide acts as a merchant of record.

16. Changes to the Agreement

Aptoide may make changes to this Agreement at any time. Aptoide will inform you, by sending a notice by e- mail describing the modifications which will become effective, with a prior notice of 15 (fifteen). In case the modifications require Certified Developer to make significant technical adjustments to the Apps, the notice period will be of 30 (thirty) days. The changes will become effective and will be deemed accepted by you: (a) immediately for those who submit new Apps to Catappult after the notification is sent; or (b) on the date specified in the notice (except changes required by law which will be effective immediately). If Certified Developer does not agree with the modifications to the Agreement, Certified Developer may terminate the Agreement, within 15 (fifteen) days from the receipt of the notice, which will be Certified Developer’s sole and exclusive remedy. Certified Developer agrees that continued use of Catappult constitutes Certified Developer’s agreement to the modified terms of this Agreement.

17. General Legal Terms

1. This Agreement constitutes the whole legal agreement between you and Aptoide and governs your use of Catappult, and completely replaces any prior agreements between you and Aptoide in relation to the Services.

2. You agree that if Aptoide does not exercise or enforce any legal right or remedy which is contained in this Agreement (or which Aptoide has the benefit of under any applicable law), this will not be taken to be a formal waiver of Aptoide's rights and that those rights or remedies will still be available to Aptoide.

3. If any court of law, having the jurisdiction to decide on this matter, rules that any provision of this Agreement is invalid, then that provision will be removed from this Agreement without affecting the rest of this Agreement. The remaining provisions of this Agreement will continue to be valid and enforceable.

4. You and Aptoide are independent contractors, and nothing in this Agreement will create any partnership, joint venture, agency, franchise, sales representative, or employment relationship between us. You will have no authority to make or accept any offers or representations on our behalf. This Agreement will not create an exclusive relationship between you and us. Nothing expressed or mentioned in or implied from this Agreement is intended or shall be construed to give to any person other than the parties hereto any legal or equitable right, remedy, or claim under or in respect to this Agreement.

5. The rights granted in this Agreement may not be assigned or transferred by either you or Aptoide without the prior written approval of the other party. Neither you nor Aptoide shall be permitted to delegate their responsibilities or obligations under this Agreement without the prior written approval of the other party.

6. This Agreement will be governed by the laws of Portugal. You agree to the exclusive jurisdiction and venue of the courts in Lisbon, Portugal.

18. P2B Regulation Complaints and Mediation for EU

1. If you are established in the European Union or if you distribute Apps to Users located in the European Union, you may submit complaints pursuant to the Regulation (EU) 2019/1150 of the European Parliament and of the Council on promoting fairness and transparency for business users of online intermediation services (“P2B Regulation”) by sending a written communication to support@catappult.io, related to the following issues: (a) Aptoide’s alleged non-compliance with any obligations set forth in the P2B Regulation which affect you in the European Union; (b) technological issues relating directly to distribution of Apps in the European Union that affect you; or (c) measures taken by, or behaviour of, Aptoide relating directly to distribution of the Apps in the European Union that affect you. Aptoide will consider and process such complaints and communicate the outcome to you.

2. Pursuant to the P2B Regulation, Aptoide identifies the following panel of mediators with which Aptoide is willing to engage to attempt to reach an agreement with Developers established in the European Union or distributing Apps to Users located in the European Union on the settlement, out of court, of any disputes between Aptoide and you arising in relation to the execution of this Agreement, including complaints that could not be resolved by means of our complaint-handling system:

  1. ADR Lab, NOVA School of Law
    Campus de Campolide
    1099-032 Lisboa
    Portugal
    https://laboratorioral.fd.unl.pt/centro-de-mediacao/
  2. Centro de Arbitragem Comercial da Câmara de Comércio e Indústria Portuguesa
    Rua das Portas de Santo Antão, 89
    1169-022 LISBOA
    Portugal
    https://www.centrodearbitragem.pt/index.php?lang=en



ANNEX I

MoR Territories

https://catappult.io/developers-distribution-policy-mor-annex-I

Annex I to the Catappult Certified Developer Distribution Agreement

MoR Territories

If you choose to do so in your Certified Developer Account, for the purposes of Clause 4.3. of this Agreement, Aptoide may, acting as your commercial agent, be the merchant of record in relation to the In-App Products sold through Aptoide App Store and certain Partner Stores to Users located in the following territories/countries and provided that Certified Developer and Partner Stores have integrated Catappult billing system into its Apps/Stores:

Åland Islands

Lithuania

Austria

Luxembourg

Belgium

Malta

Bulgaria

Martinique

Ceuta

Mayotte

Croatia

Melilla

Republic of Cyprus

Monaco

Czech Republic

Netherlands

Denmark

New Caledonia

Estonia

Norway

Faroe Islands

Poland

Finland

Portugal

France

Réunion

French Guiana

Romania

French Polynesia

Saint Barthélemy

Gibraltar

Saint-Martin

Germany

Saint Pierre and Miquelon

Greece

San Marino

Greenland

Santa Cruz de Tenerife

Guadeloupe

Slovakia

Holy See (Vatican City State)

Slovenia

Hungary

Spain

Iceland

Svalbard and Jan Mayen Islands

Ireland

Sweden

Italy

United Kingdom

Las Palmas

Wallis and Futuna

Latvia

Liechtenstein




ANNEX II

Transaction Taxes Territories

https://catappult.io/developers-distribution-policy-mor-annex-II

Annex II to the Catappult Certified Developer Distribution Agreement

Transaction Taxes Territories

If you choose to do so in your Certified Developer Account, for the purposes of Clause 4.5. of this Agreement, Aptoide may determine if the Apps and In-App Products are subject to Transaction Taxes and, if so, collect the applicable tax rate and remit it to the appropriate tax authorities, in relation to the In-App Products sold through Aptoide App Store and certain Partner Stores to Users located in the following territories/countries and provided that Certified Developer and Partner Stores have integrated Catappult billing system into its Apps/Stores:

Åland Islands

Lithuania

Austria

Luxembourg

Belgium

Malta

Bulgaria

Martinique

Ceuta

Mayotte

Croatia

Melilla

Republic of Cyprus

Monaco

Czech Republic

Netherlands

Denmark

New Caledonia

Estonia

Norway

Faroe Islands

Poland

Finland

Portugal

France

Réunion

French Guiana

Romania

French Polynesia

Saint Barthélemy

Gibraltar

Saint-Martin

Germany

Saint Pierre and Miquelon

Greece

San Marino

Greenland

Santa Cruz de Tenerife

Guadeloupe

Slovakia

Holy See (Vatican City State)

Slovenia

Hungary

Spain

Iceland

Svalbard and Jan Mayen Islands

Ireland

Sweden

Italy

United Kingdom

Las Palmas

United States of America

Latvia

Liechtenstein




ANNEX III

Applicable revenue share conditions - Apps distribution through Aptoide App Store and Partner Stores

https://catappult.io/developers-distribution-policy-mor-annex-III

Annex III to the Catappult Certified Developer Distribution Agreement

Applicable Revenue Share

Apps distribution through Aptoide App Store and Partner Stores

EntityRevenue share

Aptoide Catappult

25%

Certified Developer

75%




ANNEX IV

Applicable revenue share conditions - Apps distribution through Aptoide App Store iOS

https://catappult.io/developers-distribution-policy-mor-annex-IV

Annex IV to the Catappult Certified Developer Distribution Agreement

Applicable Revenue Share

Apps distribution through Aptoide App Store iOS

EntityRevenue share

Aptoide Catappult

20%

Certified Developer

80%




ANNEX V

Data Sharing Agreement

https://catappult.io/developers-distribution-policy-mor-annex-V

Annex V to the Catappult Certified Developer Distribution Agreement

Data Sharing Agreement

This agreement is executed on the same date as the Catappult Certified Distribution Agreement, by and between Aptoide, S.A., a Portuguese company, with the identification number ID 509987184 and principal place of business at Rua Soeiro Pereira Gomes, Lote 1, 3D, 1649-031 Lisboa, Portugal, hereinafter referred to as “Aptoide” and the entity identified as “Certified Developer” in the Catappult Certified Developer Agreement.

Together referred by “Parties” and individually “Party”. 

WHEREAS:

1. The Parties entered into a Catappult Catappult Certified Developer Agreement (the “Contract”) that may require the sharing of Personal Data between the Parties. 

2. This Personal Data Processing Agreement (Agreement) sets out the additional terms, requirements and conditions on which the Parties agree to share Personal Data under the Contract. 

AGREED TERMS

1. DEFINITIONS AND INTERPRETATION

The following definitions and rules of interpretation apply in this Agreement. 

1.1 Definitions

  1. Business Purposes: the sharing of Personal Data between the Parties under the execution of the Contract in order to allow Aptoide to manage and process payments of in-app purchases and to pay to the Certified Developer the applicable revenue share. Certified Developer may also need to use the Personal Data for its own internal business purposes.
  2. Data Protection Legislation: all applicable privacy and data protection laws including the General Data Protection Regulation ((EU) 2016/679) and any applicable national implementing laws, regulations and secondary legislation in Portugal relating to the processing of Personal Data and the privacy of electronic communications, as amended, replaced or updated from time to time, including the Privacy and Electronic Communications Directive (2002/58/EC) and the Privacy and Electronic Communications (EC Directive) Regulations 2003 (SI 2003/2426).
  3. Data Subject: an individual who is the subject of Personal Data.
  4. Personal Data: means any information relating to an identified or identifiable natural person that is processed by the Processor as a result of, or in connection with, the provision of the services under the Contract; an identifiable natural person is one who can be identified, directly or indirectly, in particular by reference to an identifier such as a name, identification number, location data, an online identifier or to one or more factors specific to the physical, physiological, genetic, mental, economic, cultural or social identity of that natural person.
  5. Permitted Recipients: The parties to this agreement, their Affiliates, the employees of each party, any third parties engaged to perform obligations in connection with this agreement.
  6. Personal Data Breach: a breach of security leading to the accidental or unlawful destruction, loss, alteration, unauthorised disclosure of, or access to, Personal Data transmitted, stored or otherwise processed.
  7. Processing, processes and process: either any activity that involves the use of Personal Data or as the Data Protection Legislation may otherwise define processing, processes or process. It includes any operation or set of operations which is performed on personal data or on sets of personal data, whether or not by automated means, such as collection, recording, organisation, structuring, storage, adaptation or alteration, retrieval, consultation, use, disclosure by transmission, dissemination or otherwise making available, alignment or combination, restriction, erasure or destruction. Processing also includes transferring Personal Data to third parties.
  8. Shared Personal Data: the personal data to be shared between the parties under the Contract.
  9. Standard Contractual Clauses (SCC): Module One (Controller to Controller) of the standard contractual clauses for the transfer of Personal Data to third countries as approved by the European Commission in Commission Implementing Decision (EU) 2021/914 of 4 June 2021.

1.2 This Agreement is subject to the terms of the Contract and is incorporated into the Contract. Interpretations and defined terms set forth in the Contract apply to the interpretation of this Agreement.

1.3 A reference to writing or written includes e-mail.

1.4 In the case of conflict or ambiguity between:

  1. any provision contained in the body of this Agreement and any provision contained in the Annexes, the provision in the body of this Agreement will prevail;
  2. the terms of any accompanying invoice or other documents annexed to this Agreement and any provision contained in the Annexes, the provision contained in the Annexes will prevail;
  3. any of the provisions of this Agreement and the provisions of the Contract, the provisions of this Agreement will prevail, in what relates to data protection matters; and
  4. any of the provisions of this Agreement and any executed SCC, the provisions of the executed SCC will prevail.

2. PERSONAL DATA TYPES AND PROCESSING PURPOSES

2.1 The Parties acknowledge that for the purpose of the Data Protection Legislation, each of the Parties will act as a separate and independent controller in relation to the Personal Data which they process.

2.2 Each of the Parties retain control of the Shared Personal Data and remains responsible for its compliance obligations under the applicable Data Protection Legislation, including providing any required notices and obtaining any required consents.

2.3 The Parties undertake to process the Shared Personal Data only for: (1) the Business Purposes and; (2) to comply legal, regulatory and compliance obligations, including without limitation as may be required in the course of litigation. The Parties shall be allowed to share the Shared Personal Data with the Permitted Recipients, subcontractors and service providers and store such Personal Data in any location.

2.4 The Shared Personal Data and the Data Subjects which the Parties may process to fulfil the Business Purposes of the Contract are the following:

  1. Personal Data Categories: IP address, date and time of the transaction; amount of the transaction; country in which the transaction was executed (based on the IP address).
  2. Data Subjects: users who make in-app purchases in the Apps integrated with Aptoide’s IAB.

3. PARTIES OBLIGATIONS

3.1 In respect to the Shared Personal Data, each Party shall:

  1. ensure that it has all necessary notices and consents in place to enable lawful transfer of the Shared Personal Data to the Permitted Recipients for the Business Purposes;
  2. give full information to any data subject whose personal data may be processed under this agreement of the nature such processing;
  3. process the Shared Personal Data only for the purposes determined in Clause 2.3. above;
  4. not disclose or allow access to the Shared Personal Data to anyone other than the Permitted Recipients;
  5. ensure that all Permitted Recipients are subject to written contractual obligations concerning the Shared Personal Data (including obligations of confidentiality) which are no less onerous than those imposed by this Agreement;
  6. ensure that it has in place appropriate technical and organisational measures, to protect against unauthorised or unlawful processing of personal data and against accidental loss or destruction of, or damage to, personal data;
  7. not to transfer any Shared Personal Data outside the EEA unless the transferor:
    1. complies with the provisions of Articles 26 of the GDPR (in the event the third party is a joint controller); and
    2. ensures that (i) the transfer is to a country approved by the European Commission as providing adequate protection pursuant to Article 45 GDPR; (ii) there are appropriate safeguards in place pursuant to Article 46 GDPR; or (iii) one of the derogations for specific situations in Article 49 GDPR applies to the transfer.

Without prejudice of the above, to the extent that this Agreement involves a transfer of personal data to a country outside the EU/EEA/UK which has not been recognised by the European Commission as offering adequate data protection, and to the further extent that Certified Developer is receiving personal data from Aptoide as a data importer: (a) the Parties hereby incorporate Module One (Controller to Controller) of the standard contractual clauses for the transfer of Personal Data to third countries as approved by the European Commission in Commission Implementing Decision (EU) 2021/914 of 4 June 2021, (“SCCs”) into this Agreement as the applicable data transfer mechanism, including the selections and information contained in Appendix A of this Agreement; (b) Certified Developer specifically acknowledges its warranty under Clause 14(c) of the SCCs in respect of making the best efforts to provide Aptoide with information relevant to the transfer risk assessment and to cooperate with Aptoide in ensuring compliance with the SCCs; and (c) if further regulatory guidance becomes available or industry standard practices develop about international data transfers, the Parties shall timely execute an amendment.

4. MUTUAL ASSISTANCE

4.1 Each party shall assist the other in complying with all applicable requirements of the Data Protection Legislation. In particular, each party shall:

  1. promptly inform the other party about the receipt of any data subject access request in respect to the Shared Personal Data;
  2. provide the other party with reasonable assistance in complying with any data subject access request;
  3. assist the other party, at the cost of the other party, in responding to any request from a data subject and in ensuring compliance with its obligations under the Data Protection Legislation with respect to security, breach notifications, impact assessments and consultations with supervisory authorities or regulators;
  4. notify the other party without undue delay on becoming aware of any breach of the Data Protection Legislation.
  5. at the written direction of the Data Discloser, delete or return Shared Personal Data and copies thereof to the Data Discloser on termination of this Agreement unless required by law to store the personal data; and
  6. provide the other Party with contact details of at least one employee as point of contact and responsible manager for all issues arising out of the Data Protection Legislation.

5. SECURITY

5.1 The Parties undertake to implement appropriate technical and organisational measures against unauthorised or unlawful processing, access, disclosure, copying, modification, storage, reproduction, display or distribution of the Shared Personal Data, and against accidental or unlawful loss, destruction, alteration, disclosure or damage of Personal Data.

5.2 The Parties undertake to implement such measures to ensure a level of security appropriate to the risk involved, including as appropriate:

  1. the pseudonymisation and encryption of personal data;
  2. the ability to ensure the ongoing confidentiality, integrity, availability and resilience of processing systems and services;
  3. the ability to restore the availability and access to personal data in a timely manner in the event of a physical or technical incident; and
  4. a process for regularly testing, assessing and evaluating the effectiveness of security measures.

6. TERM AND TERMINATION

6.1 This Agreement will remain in full force and effect so long as:

  1. the Contract remains in effect, or
  2. Any of the Parties retains any Shared Personal Data related to the Contract in its possession or control.

6.2 Any provision of this Agreement that expressly or by implication should come into or continue in force on or after termination of the Contract in order to protect Shared Personal Data will remain in full force and effect.

7. INDEMNIFICATION

7.1 Each Party shall indemnify the other against all liabilities, costs, expenses, damages and losses (including but not limited to any direct, indirect or consequential losses, loss of profit, loss of reputation and all interest, penalties and legal costs (calculated on a full indemnity basis) and all other reasonable professional costs and expenses) suffered or incurred by the indemnified party arising out of or in connection with the breach of the Data Protection Legislation by the indemnifying party, its employees or agents, provided that the indemnified party gives to the indemnifier prompt notice of such claim, full information about the circumstances giving rise to it, reasonable assistance in dealing with the claim and sole authority to manage, defend and/or settle it.

8. NOTICES

8.1 Any notice or other communication given to a party under or in connection with this Agreement must be in writing and delivered to the addresses and contacts of the Parties referred to in the Contract.




Appendix A
(to the Data Sharing Agreement)

The Parties agree that with respect to the purpose of transfer identified below, the following options in the EU SCCs are selected and information inserted when the EU SCCs are incorporated into this Agreement:

  1. Clause 7: Optional docking clause is included;
  2. Clause 11: The optional clause allowing data subjects to lodge a complaint with an independent dispute resolution body is removed;
  3. Clause 13: The option for the data exporter established in an EU member state is selected;
  4. Clause 17: The EU Member State where the governing law is stipulated in the Country shall apply, unless this is a not EU Member State, in which case it shall be Portugal, as is where Aptoide is established; and
  5. Clause 18: The EU Member State where any dispute arising from these Clauses shall be resolved is the courts of the jurisdiction stipulated in the Agreement, unless this is not an EU Member State in which case it shall be Portugal.
  6. Annex I.A: LIST OF PARTIES
    1. Data exporter:
      1. Name: Aptoide, S.A.
      2. Address: Rua Soeiro Pereira Gomes, Lote 1, 3D, 1649-031 Lisboa, Portugal.
      3. Contact person’s name and e-mail: Data Privacy Manager, personal-data@aptoide.com
      4. Activities relevant to the data transferred under these Clauses: All data processing activities agreed under the Agreement.
      5. Signature and date: Signed and dated for and on behalf of the data exporter by execution of this Agreement.
      6. Role: Data controller
    1. Data importer:
      1. Name: [To be completed by Certified Developer]
      2. Address: [To be completed by Certified Developer]
      3. Contact person’s name and e-mail: [To be completed by Certified Developer]
      4. Activities relevant to the data transferred under these Clauses: All data processing activities agreed under the Agreement.
      5. Signature and date: Signed and dated for and on behalf of the data importer by execution of this Agreement.
      6. Role: Data controller
  7. Annex I.B: DESCRIPTION OF TRANSFER
    1. Data subjects: The personal data transferred concern the following categories of data subjects: end users of the Certified Developers Apps
    2. Categories of personal data: The personal data transferred concerns the following categories of data: data strictly necessary to provide the integration functionality contemplated under this Agreement
    3. Sensitive data transferred: The sensitive personal data transferred concern the following categories of data: none
    4. Frequency of transfer: continuous throughout the Term
    5. Nature and purpose of the processing: The data processing will be as described under the Agreement and the transfer is made for the following purposes: strictly to enable the integration functionality contemplated under this Agreement
    6. Period for which personal data will be retained or criteria to determine that period: Personal Data will be retained as provided for in each of the Parties Privacy Policies
  8. Annex I.C: SUPERVISORY AUTHORITY
    1. Identify the competent supervisory authority/ies in accordance with Clause 13: Portuguese Authority for Privacy Protection (CNPD)
  9. Annex II: TECHNICAL AND ORGANISATIONAL MEASURES INCLUDING TECHNICAL AND ORGANISATIONAL MEASURES TO ENSURE THE SECURITY OF THE DATA
    1. [To be completed by Certified Developer]


Information for the Transfer Risk Assessment:


The information below is provided by Certified Developer at the time that the Agreement is executed and any further or updated information may be provided by Certified Developer in accordance with this Data Processing Appendix.

Transfer Risk Assessment information required by 14(b) of the EU Standard Contractual ClausesCompany Answers

1

Location of Company (country of Company entity incorporation and any other material Company data processing locations)

[To be completed by Certified Developer]

2

Company’s primary storage location of the data transferred

[To be completed by Certified Developer]

3

Company’s intention for onward transfer (including the estimated number of further recipients of the data or length of processing chain)

[To be completed by Certified Developer]

4

Transmission channel used (i.e. a description of the physical/technological method used to transfer the personal data to Company)

[To be completed by Certified Developer]

5

a) Is Company subject to any local laws that can require Company to disclose personal data to public authorities or authorise access by public authorities, e.g. FISA 702 in the US? Please state the relevant law.


b) Subject to any legal prohibitions on disclosing this information, has Company received any requests from any public authority to disclose personal data under such local laws referenced in a), in the past five years?

a) [To be completed by Certified Developer]


b) [To be completed by Certified Developer]

5

Details provided by Company of any relevant contractual, technical or organisational measures Company has implemented to safeguard personal data from interception or disproportionate access by public authorities, during transmission or processing. (This is in addition to Annex II of the EU SCCs).

[To be completed by Certified Developer]


Examples:


Technical: Measures for ensuring:

  1. ongoing confidentiality, integrity, availability and resilience of processing systems and services
  2. the ability to restore personal data in a timely manner in the event of an incident
  3. user identification and authorisation
  4. the protection of data during transmission
  5. the protection of data during storage
  6. physical security of locations at which personal data are processed
  7. events logging
  8. system configuration, including default configuration
  9. internal IT

Organisational: Measures/processes for:

  1. regularly testing, assessing and evaluating the effectiveness of technical and organisational measures in order to ensure the security of the processing
  2. IT security governance and management
  3. ensuring data minimisation
  4. ensuring data quality
  5. ensuring limited data retention
  6. ensuring accountability
  7. allowing data portability and erasure